My visa is about to expire, can I apply to extend it?

• Delays in preparing and submitting applications to comply with pre-commencement conditions. In this respect there can be lengthy timescales gathering evidence to support applications to comply with pre-commencement conditions, ecology, contamination and archaeology are examples of matters which can require significant periods of survey work
• Following on from the above the ability to get required experts on the site necessary to undertake the required survey work
• Delays in the determination of applications to comply with pre-commencement conditions. In this respect whilst there are deemed discharge provisions/procedures concerning certain matters, the provisions cannot be used to discharge all types of conditions
• The ability to get people on site to undertake material operations

In the circumstances, it is advisable to start considering the implementation of the planning permission early and the earlier the better. Under current legislation whilst it is possible to vary conditions, albeit potentially leading to wider issues, it is not possible to extend the life of a planning permission meaning that lawful implementation is essential to avoid the loss of that permission.

If a planning permission is lost, amongst other things it may not be granted again or may not be granted on similar terms. In the circumstances, it is advisable to seek advice given the specific facts of the case to minimise the risk of a planning permission not being lawfully implemented and expiring.

It remains the case that anyone who has symptoms, however mild, or is in a household where someone has symptoms, should not leave their house to go to work. Those people should self-isolate, as should those in their households.

Payments of the Community Infrastructure Levy (“CIL”) are tied to commencement of development, and where an instalment policy is in place, the instalments are usually tied to periods of time following commencement rather than build out rates. Therefore where a development has commenced, payments of CIL are likely to fall due in respect of a site notwithstanding that the site may have temporarily closed or build out rates have slowed.

New regulations now in force, provide some additional relief for those developers with an annual turnover of £45 million or less. Such relief will allow the Council to defer payments, disapply late interest charges, and refund late interest charges that have already been levied since 21 March 2020.

For those developers that cannot benefit from the new provisions, unless a Council has adopted an exceptional circumstances relief policy the regulations do not provide for any relief to be provided in instances where payment of CIL will create viability issues. Most Councils have not adopted such a policy, and in those circumstances the CIL liability will remain due in accordance with the payment schedule on the demand notice.

Councils are at liberty to amend their instalment policies in accordance with their own internal procedures, and the Government is encouraging Councils to explore this option to provide some relief to developers. However this will only assist in respect of any prospective instalments where the development commences after the new instalment policy has been adopted.

For those developers whose annual turnover exceeds £45 million, the Government seems to be taking the view that such developers can afford their CIL liabilities regardless of the current climate. The only concession the Government has proposed is to encourage Councils to make use of the existing discretion they have in respect of the imposition of surcharges for late payments.

If the debts owed to you pre-date Covid-19 and your debtor seemed unable to pay well before the Covid-19 pandemic took place, it is entirely possible that you will be able to present a petition on the grounds that the debtor would have been unable to pay its debts even if the Covid-19 had no effect on its financial position. We do not yet have any reliable precedent as to how the Courts are likely to deal with such cases.  Whether you are likely to succeed will depend on the exact circumstances of the debt and your debtor. There has been one case decided in August 2020 where the Court concluded that Covid-19 did not have a financial effect upon the debtor and that the circumstances which gave rise to the petition had arisen long before Covid and would have occurred in any event.  A winding up order was made in that case.  What we do know about the court’s approach is that the purpose of the Act is to allow viable companies to trade through the current times and the Court is likely to set the bar high.

Please contact us if there a debt you would like to discuss. Even if presenting a winding up petition is not available for now, there may still be other forms of legal proceedings that you can use to collect money owed to you, like county court proceedings.

The European Commission has reintroduced its “comfort letter” system for cooperation in relation to shortage of supply. This allows cooperating businesses to check what the Commission’s view of their proposals are before implementing them.

In the UK context the SMA has introduced an exemption for suppliers of healthcare services to the NHS. This allows:

• Sharing information about capacity
• Coordination of staff deployment
• Joint purchasing of goods, services and facilities
• Sharing or lending of facilities
• Division of activities, including agreeing whether to expand or reduce the volume or type of services provided by suppliers

In relation to whether the CMA will investigate cooperation, it has indicated:

• The CMA will use its discretion as to the prioritisation of its enforcement action to permit some agreements/collaboration which would otherwise potentially give rise to enforcement action (including potentially attracting fines of up to 10% of group worldwide turnover)
• The CMA will use its existing power to exempt certain agreements under the Competition Act 1998 where these are in the public interest